1. Click on icon to switch from Light Mode or Dark Mode
2. Select how you would like your font displayed.
Digital Marketing Service Terms for working with MarketBrewer LLC and, CEO and Lead Marketing Developer, Jorge Giraldez.
MarketBrewer LLC, (the “MarketBrewer”) develops custom digital marketing infrastructures for businesses. Jorge Giraldez is the CEO of MarketBrewer, and Lead Marketing Developer, (the "Marketing Developer"). The Marketing Developer provides the expertise for website development, social media management, search engine optimization, Technical SEO, Local SEO, Google Business Profile Management, text marketing, e-commerce development, Amazon Web Services, digital marketing infrastructures development, custom marketing automation, email marketing, videographer and photographer.
The Marketing Developer develops a digital marketing infrastructures for businesses to connect their business, services and products to customers through search engines, social media platforms, Amazon Web Services and Developer APIs.
MarketBrewer operates a service based on the services, which can be provided to Client.
The Client, (the “Client”) wishes to retain or contract MarketBrewer to provide the services as set out in the Scope of Work with the terms and conditions set out in this Digital Marketing Service Terms.
The (the “Scope of Work”) list the digital marketing services agreed to from both MarketBrewer and the Client, (the “Parties).
The Scope of Work may include the following services and expertise:
The Deliverables, ("Deliverables") are listed in this section. The Deliverables are agreed to from both Parties.
This Agreement supersedes any prior or current discussions, agreements or representations and warranties regarding The Deliverables of this service and Agreement.
The Client grants MarketBrewer the non-exclusive authority to perform the services from the Scope of Work with the terms and conditions of this Agreements, and any addendum.
This Agreement, and the relationship between the Parties is an independent contractor relationship, and is not intended, and is not to suggest or create a partnership, joint venture or employment relationship between The Client and MarketBrewer.
The Client shall provide assistance, technical information, and decisions to MarketBrewer, as reasonably required by MarkerBrewer in su cient time to facilitate the execution of the Scope of Work and Deliverables in accordance with any estimated delivery dates or milestones. The Client agrees to communicate with MarketBrewer to provide regular information and feedback so MarketBrewer can produce the Scope of Work and Deliverables.
Client acknowledges and agrees that MarketBrewer’s ability to carry out the Scope of Work and produce the Deliverables in a timely manner is dependent on Client’s prompt performance of its obligations herein and that any delays in Client’s performance may delay delivery of the Deliverables and its ability to provide the Scope of Work.
The Client shall have sole responsibility for ensuring the accuracy of all information provided to MarketBrewer and warrants and undertakes to MarketBrewer that the Client’s employees assisting in the execution of an e ort have the necessary skills and authority. The Client shall provide such access to its information and property as may be reasonably required in order to permit the MarketBrewer to perform Scope of Work and Deliverables.
The Client has provided MarketBrewer with a copy of any applicable internal policies or procedures and a written description of any specifications or other requirements or restrictions applying to any of the Scope of Work and Deliverables.
Client shall comply with the terms and conditions of any licensing agreements which govern the use of Third-Party Materials and Services.
Client hereby grants to MarketBrewer and the online properties served by the Scope of Work of this Agreement, a non-exclusive, royalty-free, worldwide license to use, copy, modify (as permitted herein), publicly perform, display, broadcast and transmit during the term of this Agreement (i) any text, images, logos, trademarks, service marks, promotional materials, product or service information, comments, reviews, photos, audio and video clips and other information (“Client Content”) you provide in connection with Scope of Work and Deliverables. This Agreement, title to and ownership of all intellectual property rights of all Client Content will remain with Client or Client third-party licensors. MarketBrewer may, during the term of this Agreement and thereafter, include the Client's business name (including any trade name, trademark, service mark and logo) on MarketBrewer’s website portfolio, social media accounts, slideshow presentation, marketing materials and the portfolio of Developer Jorge Giraldez.
Each Party hereby warrants to the other that it has the full power and authority to enter into the Agreement, these Terms and conditions and to perform its respective obligations hereunder.
Client represent and warrant that the Client has the right and authority to enter into this Agreement. The Client also represents, warrants and covenants that the Existing Site, any content linked to the Existing Site and any content or materials that the Client provides to MarketBrewer, do not and will not: (a) infringe on any third party’s copyright, patent, trademark, trade secret, moral right or other proprietary rights or right of publicity or privacy; (b) violate any law, statute, ordinance or regulation, including, without limitation, laws and regulations governing export control, false or misleading advertising or unfair competition; (c) be defamatory or libelous; or (d) contain viruses, trojan horses, worms, time bombs, cancelbots or other similar harmful or deleterious programming routines. The Client further represents, warrants and covenants that the product or service being promoted through any campaign is (i) lawful and (ii) not the subject of any ongoing investigation by any local, state or federal regulatory or quasi-regulatory authorities.
The Client represents, warrants, undertakes and agrees with MarketBrewer that the required digital assets and any other Client materials shall be original to the Client (or that, where any Required Materials or other Client materials are provided by a third party, it has received the necessary consents or permissions to use the same) and shall not infringe any Intellectual Property Rights belonging to a third party.
MarketBrewer shall use MarketBrewer's reasonable and best efforts in the performance of Scope of Work and Deliverables obligations under this Agreement. MarketBrewer at all times complies with any and all applicable laws, rules and regulations. MarketBrewer agrees to take reasonable or appropriate measures to protect the Client's account data, confidential information, logins credentials, and credit card information.
Client is fully responsible for any content and digital assets provided to MarketBrewer. With respect to any content created by MarketBrewer, as between Client and Market- Brewer, MarketBrewer will retain ownership of the design elements of such content, EXCLUDING any of your trade names, trademarks, service marks or logos or other proprietary elements that may be included within such content, but that predate the creation of the content. MarketBrewer does not assume any obligation to perform a legal review of your digital marketing, and you remain solely responsible for legal and regulatory compliance and for the content of the Scope of Work and Deliverables.
The Client agrees to indemnify, defend, protect and hold free and harmless MarketBrewer and MarketBrewer’s parent companies, subsidiaries, affiliates, partners, officers, members, directors, agents, contractors, licensors, service providers, subcontractors, vendors, interns and employees and each of their successors from and against any and all liabilities, damages, costs, fees, expenses, obligations, claims, fines, penalties or losses, including but not limited to all attorney’s fees and other costs of defense, arising in any way from the fault or negligence of the Client, its agents, and employees.
MarketBrewer does not assume any obligation to perform a legal review of the Client’s business, and the Client remains solely responsible for legal and regulatory compliance and for the content of the Client’s marketing services.
The Client guarantees any elements of text, graphics, photos, designs, trademarks, or other artwork provided to MarketBrewer are owned by the Client, or that the Client has received permission from the rightful owner(s) to use each of the elements, and will hold harmless, protect, and defend MarketBrewer from any liability or suit arising from the use of such elements
TO THE MAXIMUM EXTENT PERMITTED BY APPLICABLE LAW, NEITHER PARTY WILL BE LIABLE FOR ANY SPECIAL, INDIRECT, INCIDENTAL, PUNITIVE OR CONSEQUENTIAL DAMAGES (INCLUDING, WITHOUT LIMITATION, FOR CONTRACT BREACH OR WARRANTY, NEGLIGENCE OR STRICT LIABILITY), OR FOR INTERRUPTED COMMUNICATIONS, LOSS OF USE, LOST BUSINESS, LOST DATA OR LOST PROFITS (EVEN IF SUCH PARTY WAS ADVISED OF THE POSSIBILITY OF ANY OF THE FOREGOING), ARISING OUT OF OR IN CONNECTION WITH THIS AGREEMENT. THE FOREGOING EXCLUSION OF LIABILITY WILL NOT APPLY TO (i) EITHER PARTY’S INDEMNIFICATION OBLIGATIONS, INCLUDING ANY AMOUNTS PAYABLE IN CONNECTION THEREWITH; (ii) TO YOUR CONFIDENTIALITY OBLIGATIONS; AND/OR (iii) EITHER PARTY’S WILLFUL MISCONDUCT.
TO THE MAXIMUM EXTENT PERMITTED BY APPLICABLE LAW, EACH PARTY’S TOTAL LIABILITY TO THE OTHER IN RESPECT OF ANY CLAIMS ARISING OUT OF, OR IN CONNECTION WITH, THE AGREEMENT, WHETHER IN CONTRACT, TORT (INCLUDING NEGLIGENCE), BREACH OF STATUTORY DUTY OR OTHERWISE, SHALL NOT EXCEED THE TOTAL SUMS PAID OR PAYABLE BY THE CLIENT TO MARKETBREWER IN THE 6 MONTHS PRIOR TO THE CLAIM.
TO THE MAXIMUM EXTENT PERMITTED BY APPLICABLE LAW, UNDER NO CIRCUMSTANCES SHALL MARKETBREWER’S CUMULATIVE, AGGREGATE LIABILITY TO CLIENT OR ANY THIRD PARTY EXCEED THE AMOUNTS RECEIVED BY MARKETBREWER FROM CLIENT DURING THE 6-MONTH PERIOD IMMEDIATELY BEFORE THE INCIDENT GIVING RISE TO SUCH LIABILITY.
If a jurisdiction applicable to you does not allow the exclusion of certain warranties or the limitation or exclusion of liability for incidental or consequential damages, such limitations and disclaimers listed above will not apply to you. To the extent applicable law restrict MarketBrewer from disclaiming any implied warranty or limit its liabilities, the scope and duration of such warranty and the extent of MarketBrewer’s liability will be the minimum permitted under such law.
In the event of a security breach, MarketBrewer shall take prompt corrective action to cure any such deficiencies and any action pertaining to such unauthorized disclosure required by applicable federal and state laws and regulations.
If the Client suspects that their account or any of their security details have been compromised or if the Client become aware of any fraud or attempted fraud or any other security incident (including a cyber-security attack) a ecting the Client and / or MarketBrewer (together a "Security Breach"), the Client must notify MarketBrewer as soon as possible by email at webdev@marketbrewer.com or by calling Jorge Giraldez at 703.677.4988 and continue to provide accurate and up to date information throughout the duration of the Security Breach. The Client must take any steps that Market- Brewer reasonably require to reduce, manage or report any Security Breach. Failure to provide prompt notification of any Security Breach may be taken into account in MarketBrewer's determination of the appropriate resolution of the matter.
Client acknowledges that MarketBrewer, as part of this Agreement, may engage third party suppliers and other vendors and subcontractors (“Subcontractors”) from time to time to provide certain services. MarketBrewer shall supervise such services and endeavor to ensure quality standard service of Subcontractors, but MarketBrewer shall not be responsible for their failure, acts or omissions, except where such failure, acts or omissions are due to MarketBrewer's negligence.
This Agreement shall be e ective as of the time frame the Client and MarketBrewer agree and sign on the Scope of Work and and Deliverables (the "Effective Date").
This Agreement may be terminated by either party upon written 14 day notice to the other, if the other party breaches any material obligation from this Agreement and the breaching party fails to cure such breach within thirty (30) days of receipt of the notice.
The Client can terminate Agreement for any reason with 14 day notice written notice. This Agreement may be terminated by MarketBrewer (i) immediately if the Client fails to pay any fees due from the Agreement; or (ii) if the Client fails to cooperate with MarketBrewer or hinders MarketBrewer’s ability to perform the Scope of Work of this Agreement.
In the event of any termination, the Client will remain liable for all amounts due to MarketBrewer as of the effective date of termination. Due to the nature of the internet, certain information regarding the Client that was posted online pursuant to the Scope of Work and Deliverables may remain available online following termination of this Digital Marketing Service Agreement.
If paid through www.marketbrewer.com additional online payment fees apply.
If paid through Zelle no additional online payments fees apply.
The Client agrees to pay MarketBrewer any and all fee(s) as billed in accordance with this Agreement before beginning Scope of Work and Deliverables.
For services that require monthly payments, The Client agrees to pay MarketBrewer recurring monthly payment, Scope of Work, Deliverables and Agreement. The name that will appear on the Client's bank statement will be:
WWW.MARKETBREWER.COM
THE CLIENT FURTHER AGREES THAT, IN THE EVENT OF ANY TERMINATION OF THIS AGREEMENT BY CLIENT, NO REFUNDS SHALL BE GIVEN UNDER ANY CIRCUMSTANCES WHATSOEVER. THE CLIENT FURTHER AGREES TO PAY UPON CANCELLATION THE AMOUNT OF ANY CANCELLATION FEES OR OTHER AMOUNTS DUE TO MARKETBREWER AS PROVIDED IN THE AGREEMENT. MARKETBREWER IS HEREBY AUTHORIZED TO CHARGE CLIENT’S CREDIT CARD ACCOUNT OR OTHER PAYMENT MECHANISM FOR ANY AMOUNTS OWED FROM TIME TO TIME BY THE CLIENT TO MARKETBREWER.
Client shall also reimburse MarketBrewer for all reasonable costs incurred in collecting any late payments,including, without limitation, attorneys’ fees.
MarketBrewer may suspend all services of this Agreement on seven (7) days written notice until the amounts outstanding are paid in full.
Neither party may assign or transfer this Agreement in whole or in part, nor any of the rights hereunder, without prior written consent of the other party.
Neither party will be liable for any failure or delay in its performance under this Agreement due to any cause beyond its reasonable control, including acts of war, acts of God, earthquake, flood, fire, embargo, riot, sabotage, or failure of third party power or telecommunications networks, provided that the delayed party: (a) gives the other party prompt notice of such cause and (b) uses its reasonable commercial efforts to promptly correct such failure or delay in performance.
MarketBrewer retains the right to perform the same or similar type of services for third parties, other clients, and businesses during and after the term of this Agreement.
This Agreement (including any non-contractual matters and obligations arising there from or associated there with) shall be governed by, and construed in accordance with, the laws of the State of Virginia in Fairfax County. Parties all consent to the court jurisdiction, agree to accept service of process by mail, and hereby waive any jurisdictional or venue defenses otherwise available to it.
In the event that one or more of the provisions of this Agreement is found to be unlawful, invalid or otherwise unenforceable, that / those provision(s) shall be deemed severed from the remainder of this Agreement. The remainder of this Agreement shall be valid and enforceable.
If either Party wishes to change the Scope of Work or Deliverables a new agreement contract must be agreed to and signed.
Client and MarketBrewer agree to make a good-faith effort to resolve any disagreement arising out of, or in connection with, this Agreement through negotiation. Should the parties fail to resolve any such disagreement within ten (10) days, any controversy or claim arising out of or relating to this Agreement, including, without limitation, the interpretation or breach thereof, shall be submitted by either party to arbitration in Fairfax, Virginia and in accordance with the Commercial Arbitration Rules of the American Arbitration Association. The arbitration shall be conducted by one arbitrator, who shall be (a) selected in the sole discretion of the American Arbitration Association administrator and (b) a licensed attorney with at least ten (10) years experience in the practice of law and at least five (5) years experience in the negotiation of technology contracts or litigation of technology disputes. The arbitrator shall have the power to enter any award that could be entered by a judge of the state courts of Virginia sitting without a jury, and only such power, except that the arbitrator shall not have the power to award punitive damages, treble damages, or any other damages which are not compensatory, even if permitted under the laws of the State of Virginia or any other applicable law. The arbitrator must issue his or her resolution of any dispute within thirty (30) days of the date the dispute is submitted for arbitration. The written decision of the arbitrator shall be final and binding and enforceable in any court having jurisdiction over the parties and the subject matter of the arbitration. Notwithstanding the foregoing, this Section shall not preclude either party from seeking temporary, provisional, or injunctive relief from any court.
Either MarketBrewer or Client may provide the other with information that is confidential and proprietary to that Party that contains information regarding, but is not limited to, trade secrets, intellectual property, systems, know-how, contracts, prices, products, processes, inventions, computer software programs (including source and object codes), marketing or sales techniques, financial condition, costs, business interests, business records, initiatives, objectives, plans, strategies, members, customers, Plan networks, clients, suppliers, lenders, underwriters, vendors, consultants, independent contractors, attorneys, accountants or consultants ("Confidential Information"). The receiving Party agrees to make commercially reasonable efforts, but in no case no less effort than it uses to protect its own Confidential Information, to maintain the confidentiality of the disclosing Party. Each Party agrees not to disclose any Confidential Information to anyone other than employees, officers and directors of such Party, that have a need to know, and to cause all such persons to abide by this Agreement. Confidential Information shall not include (even if designated by a Party) information that is or becomes part of the public domain through no act or omission of the receiving Party, or is lawfully received by the receiving party from a third party, or that the receiving Party had in its possession prior to the date of this Agreement.
This limitation will apply for a period of one (1) year after disclosure of such confidential information.
Disclosure by MarketBrewer or Client to its attorneys, accountants, or tax advisors and sales representatives, or as may be required by law to any governmental agency or authority or to a court or arbitrator shall be conditioned on all reasonable steps being taken to maintain the confidentiality of the terms of this Agreement.
Either party shall notify the other party promptly if any such disclosure is requested or required.
Each Party acknowledges that it has read and understands this Agreement and agrees to be bound by its terms and conditions.